Overview:
The $50 million RNDC construction project located in Louisville, Kentucky, had tight deadlines and complex logistics requiring precision scheduling. Delays threatened costly overruns and construction delay claims. Precision’s consultants assisted a contractor by preparing claims and quantifying schedule delays and damages that occurred during the project’s construction.
Why CPM Schedule Analysis Was Critical
The contractor faced disputes over delays. They needed forensic schedule analysis to:
– Prove actual delays
– Identify responsibility
– Support claims
Our team provided expert CPM scheduling consulting to resolve conflicts.
How We Conducted Forensic Schedule Analysis for RNDC
1. Baseline vs. Actual Schedule Review
First, we compared the original CPM schedule to as-built records. This revealed
– Missed milestones
– Critical path disruptions
– Unapproved schedule changes
2. Delay Identification & Categorization
Next, we classified delays using forensic CPM techniques:
- Excusable Delays (weather, permitting)
- Compensable Delays (owner-caused changes)
- Concurrent Delays (shared responsibility)
3. Forensic Time Impact Analysis (TIA)
We performed window-by-window schedule analysis to:
– Quantify delay durations
– Isolate responsible parties
– Calculate cost impacts
The contractor used our report to successfully negotiate their construction claim.
As forensic scheduling construction experts, we:
- Specialize in CPM schedule delay forensic analysis.
- Deliver court-admissible reports
- Resolve disputes efficiently
Get Expert Forensic Schedule Analysis
Facing construction delays? Our CPM scheduling consultants provide: - Forensic schedule reviews
- Forensic schedule analysis
- Delay claim support
- Dispute resolution
Contact us today for a free consultation.
Precision’s team of experts consists of seasoned construction professionals who are well-versed in the various risks that companies encounter during the dispute resolution process. Construction claims management is complex; without technical forensic analysis, proving critical path delays can be nearly impossible. Whether it involves mediation, arbitration, or litigation support, Precision provides the guidance to tackle the technical challenges throughout the dispute resolution process. With years of hands-on construction experience, Precision’s construction claims experts deliver a fair and reasonable assessment to strengthen your case effectively.
Precision’s Construction Experts
From calculating schedule delays, managing claims, quantifying damages, and assessing loss of productivity. Precision’s construction dispute resolution experts thoroughly analyze each unique dispute to ensure optimal outcomes.
Precision’s construction experts provide the following construction claims services: